Construction & Trades

Unconditional Lien Waiver & Release

Releases mechanics lien and bond claim rights unconditionally upon signing, regardless of whether payment has cleared. Covers both progress and final payment variants.

📄 1 signer📅 30-day expiry🏷 Construction & Trades🔖 lien-waiver, construction, unconditional

About this template

The Unconditional Lien Waiver & Release is a ready-to-use construction & trades template you can send for signature in minutes. It is written for 1 signer (claimant) and, by default, expires 30 days after it is sent if left unsigned. It covers lien waiver, construction, unconditional. Like every Abundera Sign template it is a convenience draft structured for ESIGN Act and UETA compliance, not a substitute for legal advice. Each signed copy is sealed with PAdES-LTA digital signatures, dual RFC 3161 timestamps, and a tamper-evident evidence package in WORM storage.

Document Preview

# Unconditional Lien Waiver & Release **Waiver Type:** ___________ **State:** ___________ **Date of Waiver:** ___________ --- ## Identifying Information **Claimant (Name of Contractor, Subcontractor, Supplier, or Other Person):** ___________ **Claimant Address:** ___________ **Customer / General Contractor:** ___________ **Owner of Property:** ___________ **Property / Project Description:** ___________ **Property Address:** ___________ ---

Fields (19)

waiver type
radio · required
project state
select · required
waiver date
date · required
claimant name
text · required
claimant address
textarea · required
customer name
text · required
owner name
text · required
project description
textarea · required
property address
textarea · required
payment amount
currency · required
job description
text · required
through date
date · required
final payment amount
currency
disputed claims
textarea · required
retention amount
currency
project state
select
claimant printed name
text · required
claimant title
text · required
claimant company
text

Related Construction & Trades templates

Architectural Services Agreement
Certificate of Substantial Completion
Conditional Lien Waiver & Release
Construction Bid / Proposal
Construction Change Order
Construction Punch List & Sign-Off

All 12 Construction & Trades templates →  ·  Browse all templates →

Send this template with cryptographic proof

Every signed document gets PAdES-LTA digital signatures, dual RFC 3161 timestamps, and a tamper-evident evidence package sealed in WORM storage.

Try the DemoView PricingFounding Member — 50% Off